ILLINOIS POLLUTION CONTROL BOARD
June 7,
1973
VILLAGE OF
ANTIOCH
)
#73-125
v.
ENVIRONMENTAL PROTECTION AGENCY
)
OPINION
AND
ORDER OF THE BOARD
(BY SAMUEL T. LAWTON,
JR.):
The Village of Antioch seeks a variance from Rule 404(f)
of the
water Pollution Regulations which limits discharges of BOD to
4 mg/i
and suspended solids to
5 mg/i subsequent to December 31,
1973.
The
Agency believes that this implicitly includes a variance from Rule
407(b), limiting phosphorus discharge to
1 mg/i and Rules 921(d) and
1002(a) respecting project completion schedules.
Petitioner’s present sewage treatment plant consists of an acti-
vated sludge plant and tertiary lagoon system.
Final chlorinated
effluent is discharged to Sequoit Creek,
an intermittent stream having
a dilution ratio of less than one to one, discharging into Lake Marie
and the Fox-Chain-Of—Lakes within the Fox River basin.
Agency surveil-
lance indicates that petitioner’s effluent presently complies with Rule
404(a)
limiting BOD to
30 mg/i and suspended solids to 37 mg/i.
Petitioner’s grab samples indicate an average flow of .736 NGD, an
average BOD of
5 mg/i and an average suspended solids of
9 mg/i, suggest-
ing a very high quality of effluent even at the present time.
Agency
grab samples, while somewhat higher, likewise indicate compliance
with present regulations, but inability to meet the standards provided in
Rules 404(f) and 407(b).
In addition, fecal coliform counts are ex-
tremely low.
Petitioner has embarked on a program of upgrading its treatment faci-
lity.
On December 7,
1972,
the Agency issued a permit for improvement
and expansion of the treatment plant.
The estimated cost is $525,000.
Petitioner has $100,000 on hand and an. approved revenue bond issue
of $257,500.
Because of the current~status of the Lake County region-
alization plan,
the proposed project has not been approved for State
and Federal
grants.
Accordingly,
revised engineering plans were sub-
mitted and a revised State and Federal grant application filed.
At the
time of the issuance of the Agency permit, petitioner did submit an
approved project completion schedule,
in anticipation of State and
Federal grant approval.
The delays that have now arisen are attributable
to the requirements of grants and regionalization and, accordingly,
the project completion schedule previously filed is no longer achiev-
able.
8
—
233
The Agency recommends that in consideration of the foregoing
and the high quality of petitioner~spresent effluent, a six-month
variance be granted to the Village of Antioch from Rules 404(f)
and
407(b)
and 921(b).
While the recommendation proposes the variance
be for a period of six months from the date of the Order, we believe
what the Agency intended was that it be six months from the operative
date of Rules 404(f)
and 407(b); otherwise, the variance would have no
significance.
The Agency also recommends that
a variance be granted
with respect to Rule 1002(a)
to enable the submission of a project
completion schedule showing a completion date later than December 31,
1973.
We concur.
The hardship imposed on the petitioner by insisting
on compliance with the foregoing Rules greatly outweighs any burden
on the community from the grant of the variance as requested.
This opinion constitutes the findings of fact and conclusions of law
of the Board.
IT IS THE ORDER of the Pollution Control Board:
1.
That the Village of Antioch is granted
a variance from
Rules 404(f),
407(b)
and 921(d)
of the Water Pollution
Regulations until June
7,
1974;
2.
Variance is granted to the Village of Antioch from Rule
1002(a) to enable petitioner to file a project completion
schedule showing
a completion date no later than June
7,
1974.
I, Christan Moffett, Clerk of the Pollution Control Board, certify
that the above Opinion and Order was adopted on the Jday
of
June,
1973, by a vote of
4
to
___________
—2—
8
—
234