ILLINOIS POLLUTION CONTROL BOARD
August 1, 1974
TEXACO, INC. (Lawrenceville Refinery),
Petitioner,
V.
)
PCB 74—135
ENVIRONMENTAL PROTECTION AGENCY,
Respondent.
James P. Peyton, attorney for Petitioner.
John Palinscar, attorney for Respondent.
OPINION AND ORDER OF THE BOARD (by Dr. Odell)
On April 11, 1974, Texaco, Incorporated (Texaco) filed
with the Illinois Pollution Control Board (Board) a Petition for
Variance from Rule 206(c) of Air Pollution Regulations, Chapter 2
(Chapter 2) until September 15, 1974.
Texaco operates a petroleum refinery adjacent to the
southern boundary of Lawrenceviile, Illinois, which has a population
of 5,900. This refinery manufactures principally liquified
petroleum gas, motor gasolines, aviation fuels, diesel and heating
oils, heavy fuel oil, and asphalt, utilizing approximately 84,000
barrels of crude oil per calendar day in the manufacturing process.
The refined products are distributed for consumption in southern
Illinois, as well as in Indiana, Kentucky, Ohio, Missouri, and
other states. Approximately 600 persons are employed at this
refinery.
The specific emission source which is the subject of this
Petit.ion.for Variance is the catalyst regeneration section of a
Fluid Catalytic Cracking Unit. By a combination of thermal and
catalytic cracking, this unit converts high boili~ig—range gas oils
intoLP gas, gasolines, furnace oil, fuel oil, and coke~. The con-
version is accomplished by mixing the gas oils with air and burn-
ing them in a regenerator vessel. During this process carbon
monoxide is released to the atmosphere in a concentration of
62,000 parts of CO per million parts of air.
Texaco is installing a Carbon Monoxide Boiler, at a cost
of $3,270,000, to control the carbon monoxide emissions which are
the subject of this Petition for Variance. Originally, Texaco
had planned to have its Carbon Monoxide Boiler operative by
December 31, 1973. However, equipment delivery delays and scarcity
of critical craft manpower has revised Texaco’s time schedule as
follows:
—
251
—2—
January 20, 1972
Awarded construction contract
October 18, 1972
Commenced construction
June 15, 1974
Complete construction
September 15, 1974
Commence operahion
Texaco alleges that the period from June 15 to September 15, 1974,
is needed to inspect and test the new equipment to avoid possible
injury to personnel or the equipment.
Petitioner stated that the construction delays, which were
due to tardy equipment deliveries and scarcity of critical craft
manpower, were beyond the control of Texaco and their construction
contractor, Bechtel. Texaco alleges that compliance with “Rule
206(c)
prior to the forecasted operational date (September 15, 1974) of
the Carbon Monoxide Boiler would necessitate shutdown of the Fluid
Catalytic Cracking Unit” because of limited storage for charge stock
for the latter Unit, “Cessation of operations would result in a
most unreasonable and arbitrary hardship not only on Petitioner,
but also on Texaco’s distributors and retailers, its employees, and
the general public.” Petitioner claimed that granting this Variance
would have no adverse effect on the public because there is very
little difference in the ca~rbonmonoxide concentration upwind and
downwind from the refinery, as shown by the following results from.
a survey by an outside firm, Air Resources Incorporated, of ambient
air at the perimeter of the plant:
~nMonoxide~oncentration~rn~
~einterval
~indof
~nw~of
~iner~
~iner
1 hour max.
8 hour max.
15 mm. arithmetic mean
A Recommendation was received from the Environmental
Protection Agency (Agency) on June 10, 1974. On the basis of the
catalytic unit charge of 45,000 barrels per day of gas oil, the
Agency calculated carbon monoxide emissions as 25,800 pounds per
hour in a concentration of 62,000 parts of carbon monoxide per
million parts air. Thus, Petitioner currently operates in violation
of Rule 206(c), However, Petitioner is installing a Carbon Monoxide
Boiler to control its emissions by September 15, 1974. There are no
other similar CO sources in the area, and no citizen interviews
were conducted by the Agency because carbon monoxide is odorless and
can be detected only by instrumentation. “The Agency is of the
opinion that the proposed control program, if properly designed and
operating, will achieve compliance with Rule 206(c),” The Agency
(I) denies Petitioner’s alleged economic hardship in this case, but
(2) recognizes that “the hardships caused by a plant shutdown would
be a loss of earnings for Petitioner’s employees, and a disruption
of gasoline and,.other important fuel supplies for the public.” The
Agency recommended that Petitioner be granted a Variance from Rule
206(c)~untilSeptember 15, 1974, subject to certain conditions,
—3—
A hearing was held in Lawrenceville, Illinois, on June
13, 1974, Three Texaco employees testified concerning the
operation of the refinery. Robert B. McBride, Chief Engineer,
explained the delays in the construction of the Carbon Monoxide
Boiler. The first notification of delay from the construction
contractor (Bechtel) was in their progress report for the month
ending September 30, 1973 (Exhibit 2; R,9), At this late date,
no ~alternate solution was available except to complete installation
of the CO Boiler as soon as possible.
Mr. Joe W. Garrison, Supervisor of Air and Water Conservation,
described the ambient air survey that was conducted at the refinery
by Air Resources Incorporated. The samples were taken over a 30~
day period on the top of a van, both upwind and downwind, around
the perimeter of the refinery (R,l9, 21). The amounts of carbon
monoxide measured (with a gas chromatograph) were~tonsiderably
below levels which would be dangerous to human health (R,20), The
carbon monoxide is dispersed from stacks approximately 200 feet
Mr. A.L, Bishop, Plant Manager, explained the highly inte-
grated operation of the refinery and, therefore, if the Fluid
Catalytic Cracking Unit were,shut down cessation of all operations
would necessarily soon follow.
The “Agency is convinced of Petitioner’s good faith efforts”
and recommends that the Variance be granted “subject to the con-
ditions expressed in the Agency Recommendation as amended” (R.30).
The Board concurs except that the suggested condition con-
cerning a Performance Bond ~does not seem necessary at this time,
Texaco committed itself in 1972 to installing a $3,270,000 Carbon
Monoxide Boiler and construction of it was to be completed by
June 15, 1974, according to the record in this case, The main
objective now is proper operation of the equipment to adequately
control carbon monoxide emissions, This Opinion constitutes the
findings ~of fact and conclusions of law of the Board,
IT IS THE ORDER of the Illinois PollutioB Control Board
that Petitioner is hereby granted a Variance from Rule 206(c)
of Air Pollution Regulations, Chapter 2, for its Fluid Catalytic
Cracking Unit at Lawrencevilie, Illinois, from January 1, 1974,
to September 15, 1974, subject to the following conditions:
(a) Petitioner shall make timely application for all
necessary operating permits.
(b) Petitioner shall submit a progress report on
August 10, 1974, to the Agency at the following
address:
—4
Environmental Protection Agency
Division of Air Pollution Control
2200 Churchill Road
Springfield, Illinois 62706
I, Christan L. Moffett, Clerk of the Illinois Pollution
Control Board, hereby certify that the ove Opinion and Order
was adopted on the j~±dayof
,
1974, by a vote of
__
toO.
(~).J~
j
~stanL,Mt
13—
254