ILLINOIS POLLUTION CONTROL BOARD
November 15, 1989
ROWE FOUNDRY & MACHINE
COMPANY,
Petitioner,
V.
)
PCB 89—122
(Variance)
ILLINOIS ENVIRONMENTAL
PROTECTION AGENCY,
Respondent.
DANIEL O’CONNELL APPEARED ON BEHALF OF THE PETITIONER.
JAMES O’DONNELL APPEARED ON BEHALF OF THE RESPONDENT.
OPINION AND ORDER OF THE BOARD (by J. Marlin)
This matter comes before the Board on an August 1, 1989
Petition for Variance Extension filed, by Rowe Foundry & Machine
Company (Rowe). Rowe requests an extension of the variance
granted in PCB 81—49 and extended irrPCB 88—21. Rowe requests an
extension of a variance from 3.3 Ill. Adm. Code 216.381 which
prohibits the emissions of carbon, monoxide from a cupola if the
concentration of carbon monoxide in the gasses emitted from the
cupola exceeds 200 ppm corrected
to
50 excess air.
A hearing was held at Clark County Courthouse, Marshall,
Illinois, on September 27, 1989. No members of the public
participated in the proceedings. The Illinois Environmental
Protection Agency (Agency) filed its Recommendation on September
28, 1989.
Background
The facts of this case remain substantially unchanged from
those outlined in the Board Order PCB 88-21 of February 23,
1989. Therefore, only a brief outline of the facts are included
herein.
Rowe operates a gray—iron foundry for the production of
counterweights. The facility is located in Martinsville, Clark
County, which is considered an attainment area for carbon
monoxide.
The subject of this variance extension is a Whiting No. 9
Cupola. The cupola is charged with approximately 3,300 pounds of
~oundry coke, 1400 pounds of limestone and 28,000 pounds of scrap
on per hour. A scrubber controls particulate emissions.
bon monoxide emissions remain uncontrolled.
1n5 ~
2
History
Rowe was granted a five year variance on February 10, 1983,
(PCB 81—49). On February 23, 1989, Rowe was granted a
variance
extension until August 1, 1989, (PCB 88—21). Rowe now requests
extension of variance until February 1, 1990.
Hardship
Rowe states in its petition that it can neither immediately
comply with Section 216.381 nor fulfill the original compliance
plan because of schedule disruptions that were not forseeable
when it submitted its original compliance plan. (Pet. 19—15).
Rowe states that unforeseen problems with the supplier of
the charging system and electrical demand restrictions placed on
the starter for the blower motor by Central Illinois Public
Service Company have caused unavoidable delays in construction of
the new cupola and scrubber system. (Pet. at 15). Rowe states
that shutting down operations is the only means to achieve
immediate compliance. (Pet. at 16).
The Agency in its recommendation states that Rowe had made
satisfactory progress during the variance extension granted in
PCB 88—21. (Ag. Rec. at 4). Also the Agency states that Rowe
has expended approximately $380,000 toward installation of the
new equipment. (Ag. Rec. at 4).
Therefore the Board finds that Rowe has presented adequate
proof that immediate compliance would constitute an arbitrary or
unreasonable hardship.
The Board hereby grants Rowe’s requested variance extension
from 35 Ill. Adm. Code 216.831 until February 1, 1990. However,
the Board grants the variance subject to certain conditions, set
forth in the Order below.
This Opinion constitutes the Board’s findings of fact and
conclusions of law in this matter.
ORDER
The Board grants extension of variance to Rowe Foundry
Machine Company from 35 Ill. Adm. Code 216.381 until February 1,
1990, subject to the following conditions:
1.
Rowe
will continue to pursue the construction and
installation of a new
cupola
with a
carbon monoxide
control system and shall achieve compliance by February
1, 1990.
2. Rowe shall submit quarterly reports to the Agency on the
operation of the cupola.
1’~5 ~
3
3. Rowe shall implement and maintain the housekeeping and
maintenance plan set forth below:
A. The size of the scrap iron pieces entering the
cupola shall be small enough so as to prevent
clogging of the cupola, thus necessitating the
momentary shutdown of the pollution control
equipment. At no time shall Rowe attempt to melt
pieces of iron longer than 30 inches.
B. All of the necessary replacement parts, including
fan blades and bearing sets, for the pollution
control equipment shall be on hand.
C. Ensure that all pollution control equipment and
associated ductwork on the existing cupola are
maintained such that emissions from the source
continue to be emitted solely from the top of
Rowe’s existing stack.
D. Implement a detailed housekeeping program designed
to keep the facility’s roofs, interior working
areas and adjacent outside areas clean of
particulate matter and those areas of the plant
free of foundry sand where the use of the sand is
not required for the molding in cooling of metal.
The housekeeping program shall consist of sweeping
all hard outside surface areas at least weekly.
Foundry sand shall be regularly swept up on the
inside of the foundry buildings and scooped off the
production floors. Accumulations of particulate
matter shall be removed from the roof at least
monthly.
Rowe shall inform all plant personnel of the
housekeeping and maintenance plan and that plan
must be complied with at all times.
4. Rowe shall be limited to operation of the cupola twice
weekly.
5. Rowe shall be limited to a production of 12.79 tons of
iron poured per hour.
6. Rowe shall dismantle and remove the current cupola upon
completion of construction of the proposed system.
7. Rowe shall verify with documentation to the Agency’s
Division
of
Water Polution Control that the existing
wastewater treatment facility is adequate to handle the
discharge from the proposed cupola and scrubber system.
1fl5 21~
4
8. Rowe shall not violate the National Ambient Air Quality
Standards for carbon monoxide.
9. Rowe shall submit any necessary permit applications to
continue to operate its current cupola no later than 45
days after grant of the variance extension.
10. Within 45 days after the date of this Order, Rowe
Foundry & Machine Company shall execute and send to the
Agency a Certificate of Acceptance of this variance by
which it agrees to be bound by the terms cnd conditions
contained herein. The executed Certificate shall be
sent to:
Illinois Environmental Protection Agency
Attention: James O’Donnell
Enforcement Programs
P.O. Box 19276
2200 Churchill Road
Springfield, IL 62794—9276
The 45—day period shall be held in abeyance for any
period during which this matter is appealed. Failure to
execute and forward the Certificate within 45 days
renders this Variance void and of no force and effect.
The form of the certification shall be as follows:
CERTIFICATION
I, (We)
,
having read
the Order of the Illinois Pollution Control Board in PCB 89—122,
dated November 15, 1989, understand and accept the Order,
rcali~ing that such acceptance renders all tern~ an~ c~niitior~s
thereto binding and enforceable.
Petitioner
Authorized Agent
Title
Date
11. Quarterly reports shall be sent to:
Mr. John Justice, Regional Manager
Division of Air Pollution Control
Illinois Environmental Protection Agency
2009 Mall Street
Collinsville, IL 62234
1’)52 IC’
5
Section 41 of the Environmental Protection Act, Ill. Rev.
Stat. 1987 ch. 111 ~ par. 1041, provides for appeal of final
Orders of the Board within 35 days. The Rules of the Supreme
Court of Illinois establish filing requirements.
IT IS SO ORDERED.
I, Dorothy M. Gunn, Clerk of the Illinois Pollution Control
Board, hereby certify that the above Order was adopted on
the
/..6~
day of
~
,
1989, by a vote
of
7-~
Dorothy M./,i~unn, Clerk
Illinois ~ollution Control Board
1fl5 217