ILLINOIS

POLLUTION CONTROL BOARD

May 10, 1972

CHICAGO-DUB UQUE FOUNDRY CORP.

v.

)

#

71—309

~NV1RONMENTAL

PROTECTION AGENCY

Supplemental Opinion and Order

of

the

Board (by

Mr.

Currie)

On October 14,

1971, we granted

a variance setting

a May 12, 1972 date for completion of petitioner~s program of

foundry particulate control, The

company filed its bond,

ordered the equipment,

and received a permit for the installation,

all

in due time. Delays

in equ~pment delivery, including a

strike at a supplier contractor, have made it impossible to

meet the May 12 date. The Agency joins in the plea that we

extend the compliance date to July 12, 1972, pointing out

that

the company has done everything in its power to expedite

delivery.

The May

12,

1972 date for compliance and for forfeiture

of the bond is hereby extended to July 12, 1972.

I, Christan Moffett, Clerk of the Pollution Control Board,

certify

that the

~oard adopted the

above Supplemental Opinio~iand Order

thisJ~~~day of~~

,

1972,

by

a

vote of~~