ILLINOIS
POLLUTION
CONTROL
BOARD
February
28,
1974
IN
THE
MATTER
OF:
PETITIONiOF~i7ARIANCEFOR:
)
PCB
73-558
A.B. DICK COMPANY
OPINION AND ORDER
OF THE
BOARD
(by Dr. Odell)
On December 26,
1973,
the Petitioner, A.B. Dick Company,
filed with the Illinois Pollution Control Board
(hereinafter Board)
a petition for a variance for two months, from December 31,
1973,
to February 28,
1974,
from Rule 205(f) and Rule 203(b)
of Chapter
2,
Illinois
~ir
Pollution
Regulations.
Petitioner
operates
a plant in Niles which is primarily
engaged in the
assembly o~T
photocopy equipment and the manu-
facture of photocopy
sepal
~s.
Pctitioner~sfacility includes a
toner concentrate process.
The
tee-enonth variance was requested
to provide enough time
to
instal
a baghouse for particulate
emissions and recovery of organic emissions in the toner
concentrate process.
When the baghouse was purchased from the
Mikropul Division of United States Filter Corporation on June
6,
1973,
the supplier promised delivery by September 17, 1973,
and
it was to be in operation by November~15, 1973.
However, ship-
ment of the equipment was rescheduled four times, and it was
finally expected to arrive at Petitioners plant on December
28,
1973, which was too late
to have it installed by December 31,
1973.
On February
8,
1974,
the Board received a Recommendation
from the Environmental Protection Agency
(hereinafter Agency)
concerning this petition for a variance.
The Agency believes
that the “Petitioner is
in violation of Rule 203(a), not Rule
203 (b),
since it was not in compliance with Rule 203 (b) on April
14,
1972.
The toner concentrate process presently consists of a
blender used to mix ethyl alcohol, carbon black, and dye.
The
ethyl alcohol is evaporated in a Bowen Spray Dryer which vents
to a high efficiency cyclone for product collection.
Effluent
from the cyclone vents directly to the atmosphere.
Agency calculations confirm Petitioner~scalculations
which indicate particulate emissions
(based on a mass balance
across the system)
of
1.2 lbs/hour of Dry Powder Pigment.
The
process weight rate is 25.0 lbs/hour, thereby allowing an emission
rate of
.24 lbs/hour under Regulation 203(a).
The design
11
—403
—2—
efficiency of the baghouse is 99,
and when it is installed it
will reduce particulate emissions to .012 lbs/hour.
The
25
lbs/hour
process weight rate contains,
as the
major component,
18.8 lbs per hour of ethyl alcohol.
The
entire amount of this photochemically reactive solvent is emitted
to the atmosphere,
in violation
of
Rule 205(f), effective on
December 31,
1973, which limits emissions
of
photochemically
reactive solvents to
8 lbs/hour.
Upon installation of the bag-
house, Petitioner proposes
to
duct
the
baghouse effluent into an
existing ethyl alcohol
adsorption unit in order to reclaim the
effluent,
as well as to reduce the
emissions of photochemically
reactive solvents
to less than
8
lbs/hour.
The Agency believes that Petitioner’s
control program is
sufficient to bring it into compliance with
Rules
203(a) and
205(f).
The
Agency
has received no complaints
from citizens
regarding the operations of Petitioner’s
facility
or the granting
of
a variance
in this case,
The Board finds that since Petitioner
has been diligent
in its
attempts
to
achieve
compliance, and that
since the delays
in delivery of the baghouse were not the fault
of Petitioner,
that it
would
be
arbitrary and unreasonable
to
deny a variance
for the short period of time requested by Petitioner.
Therefore,
the Board will grant this variance as specified below.
This Opinion constitutes the findings of fact and con-
clusions of law of the Board,
ORDER
IT
IS THE ORDER of the Pollution Control Board that
Petitioner be granted
a variance from Rules
203(a)
and 205(fY
until February 28, 1974,
subject to the following conditions:
a.
Petitioner shall notify the
Environmental
Protection Agency on the date that all control
equipment is installed and fully
operational.
Said notification shall be made to:
Environmental Protection Agency
Division of Air Pollution Control
Control
Program Coordinator
2200 Churchill Road
Springfield,
Illinois 62706
b.
Petitioner shall apply for all
necessary
operating permits for the new control
equip-
ment
from the Environmental Protection
Agency.
Mr. Dumelle abstained.
I, Christan L. Moffett, Clerk of the Illinois Pollution Control
Board, hereby certify 4that the above Opinion and
Order
was
adopted
on the ~~day
of
~
1974,
by a vote of
~
to
O
Christan L~Mof~t, ~erk
11 —404